Editor Login

 JEF Group can also supply many extras to make your event special:

  • Road cones
  • Start and finish gantries
  • Timeclocks
  • Advertising frameworks and hoardings
  • Flag poles
  • Rostrums
  • Ticket kiosks
  • Hospitality tents
  • Chairs and tables

If the ground is wet or you are worried about damage caused by vehicles on site, we can supply and lay artificial roadway.

We also provide small seating units manufactured to order.

If you require anything for your event which is not on the list, please ask us.

CHAS logo SAFE logo

Company Registration Number: 0194214


1. Quotations remain valid for three months from the date of receipt of the quotations by the Hirers and are subject to the Owners having available material and labour at the time of receipt of the Hirers' order and the Owners receiving reasonable notice to commence work after receipt of the Hirers' order, provided that the said notice to commence work shall not be given more than six months after the date of acceptance unless it is otherwise agreed in writing by the parties concerned.

2. The period of hire starts from commencement of erection to completion of dismantling.

3. The Owners will exercise all proper care to ensure that the scaffolding is soundly and adequately constructed for the purpose for which the Hirers have requested, and that when constructed it complies with the requirements of the Building (Safety, Health and Welfare) Regulations, 1948, it being the responsibility of the Hirer for whom we erect the scaffolding to carry out periodic inspections and to ensure that the same is used in accordance with, and continues to comply with this regulation.

4. The Hirers shall indemnify the Owners against all claims, damages and costs arising out of the scaffolding except that where such claims damages and costs are due to the negligence of the Owners the latter shall be responsible for and indemnify the Hirers against such claims, damages and costs; provided that it shall be a condition precedent to the Owners bearing responsibility therefor that the Hirers give forthwith to the Owners written notice specifying the said damage.

5. When erecting and dismantling cradle equipment and scaffolding every reasonable precaution will be taken to prevent damage to property, buildings, equipment or fittings in, on or adjoining the site, but this quotation is submitted on the express condition that the Hirer shall indemnify the Owners against all claims for accidental damage arising through work on or in the erection and dismantling of the cradle equipment or scaffolding.

6. The Hirers and Owners respectively shall effect and keep in force during all material times policies or insurance of adequate amounts against their respective liabilities under any statute in force for the time being in respect of injuries to persons and at Common Law in respect of injuries to persons or property arising out of and in the course of the execution of the work and/or arising out of and in the course of the employment of any workmen employed by them respectively.

7. All materials let out on hire remain always the property of the Owners. The Hirer shall, on receipt of any goods provided and/or supplied by the Company, inspect same and shall maintain such goods in a fit and proper condition insured against all risks damage and loss until the return of such goods to the Company. In the event of default in payment by the Hirers, the latter shall, so far as they lawfully can, assist the Owners to resume possession of the goods.

8. In the case of materials being obtained on HIRE only, the Hirer will be responsible for the proper care and maintenance of the materials. Hire rates are strictly from "Rack to Rack" and continue until the Hirer returns the materials to our yard.

9. Any work or alterations required by the Hirers not specifically covered in our quotation will be carried out at Daywork rates quoted, plus expenses incurred, unless otherwise agreed. Where any work is carried out at Daywork rates, the total number of hours booked, as shown on the Owners' daily time cards or time sheets, will be accepted by the Hirer and become chargeable at the rates shown in this quotation.

10. Receipts for all material delivered to and from the site shall be issued in the usual manner, in the absence of the Hirer's representative the Owners' records shall be forwarded to and be accepted by the Hirers as a true record. The Hirer further undertakes not to remove any equipment or material the property of the Owners from the site to which originally consigned without having obtained the prior written consent of the Owners.

11. The Hirers shall pay in respect of any materials lost the full current Catalogue price less 10 per cent., and in respect of materials damaged the cost of repair, except in the case of damage by fire, when the full re-instatement value as determined by the Owners shall become payable.

12. The Owners will not be responsible for consequential loss caused by the negligence, acts of defaults of any of their employees; the Owners are insured in respect of Workmen's Compensation and Public-Liability.

13. The quotation is based upon the rates of wages and other emoluments and expenses payable by the Owner to workpeople engaged upon the erection of scaffolding in accordance with the rules or decisions of the National Joint Council for the Building Industry applicable and current at the date of the quotation. Increases or decreases in costs which are consequent upon changes in the said rules or decisions shall be a net addition to or deduction from the price quoted.

14. The Hirers will be responsible for obtaining the necessary permission for scaffolding to encroach upon pavements and for the fixing and maintenance of any lights needed during darkness, unless otherwise agreed.

15. During the continuance of this contract the wages and condition of employment of the employees and workmen of the Owners and the Hirers shall be such as may from time to time be prescribed by the National Joint Council for the Building industry, and the Owners and the Hirers hereby mutually agree respective to pay and observe the same accordingly. If either party shall commit a breach of this clause, then the other party shall be entitled (without prejudice to any other right or remedy) to be indemnified by the party so in breach against any loss or damage accruing from or arising out of or connected with such breach.

16. If completion of the works specified in the quotation herein be delayed:-

(i) by force majeure, or
(ii) by reason of any exceptionally inclement weather, or
(iii) by reason of loss or damage by fire, or
(iv) by reason of civil commotion, local combination of workmen strike or lock-out affecting any of the trades employed upon the works, or
(v) by delay on the part of other contractors or tradesmen engaged by the Hirers in executing work not forming part of this contract, or
(vi) by inability beyond the control of the Owners to secure such labour and materials as may be essential to the proper carrying out of the works,

then upon the happening of any such event the Owners shall immediately give notice thereof in writing to the Hirers and a fair and reasonable extension of time for completion of the works shall thereafter be agreed between the parties and in default of the agreement shall be settled by Arbitration in accordance with Condition 18 hereof.

17. Drawings or plans which are submitted in connection with this Quotation are the sole property of J.E.F. Scaffolding Ltd. and must not be communicated to any third parties without our consent. Where such drawings are submitted we can accept no responsibility for damage or occurrence which results from the alteration of such specification and design.

18. The Owners will accept no responsibility whatsoever for damage to roofs where work is carried out on or against same.

19. In the event of any disagreement arising in connection with or out of any contract placed on this quotation the matters in dispute shall be referred to arbitration in accordance with the Arbitration Act, 1950.

20. On Sales of all New and Second hand materials, title will not pass to the new Owners until all invoices are paid in full, and the onus is on the buyer to check its worthiness before use.

21. Where Hirer has no account with Owners, payment for Hire Only must be made on delivery and on Erection and Hire-payment must be made on completion of erection.

22. On Hire/Erection and Hire Only: (When delivery and collection is by the Owners) Termination of hire must be made in writing othervilc.t: Hire will be charged up to the point of collection.

23. Acceptance of this Quotation either verbally (by phone) or in writing implies acceptance of all Conditions as stated.

24. The Hirer to be responsible for application to Power/Phone Companies for insulation and protection of all cables within the proposed area) of scaffold erection - prior to erection.

25. We normally expect three working days notice before commencing work or making alterations.

26. Interest will be charged at base rate + 3 per cent. after our 30 day credit period has elapsed.

27. The above Conditions of Contract also apply to crowd barriers, security fencing, stages seating stands. cones, kiosks, tables and chairs, flagpoles and all equipment supplied on hire by the Owners. Missing or damaged crowd control barriers, fencing panels, seats, chairs and tables will be charged for at the full replacement cost.

 At JEF Group we take the Health and Safety of your customers and our employees very seriously.

We are fully insured, and provide our Company Health and Safety Policy, a Risk Assessment and Method Statement for each event we carry out.

JEF is an accredited contractor under SAFE Contractor - the fastest growing Health and Safety accreditation scheme in the UK.

JEF is also an accredited contractor under the Contractors Health and Safety Assessment Scheme (CHAS), the market leader for Health and Safety pre-qualification in the UK.


CHAS logo SAFE logo

Company Registration Number: 0194214

Security Fencing Panels

We hire, deliver and supply security fencing for temporary enclosures and partitions where the safety and security of the public is an issue.
Our fencing can also facilitate gate entry to events throughout the UK and Ireland.
JEF Group supply security fencing panels of 3.5 metres x 2 metres, in excellent condition, with rubber or concrete bases. If extra privacy or greater security is an issue at your event we can also prop the fence and supply screening.

White Picket Fencing

To enclose a VIP or special area we can supply white picket fencing with pedestrian gates. Create a village green atmosphere or enhance your wedding reception.

We offer a complete professional service for any event, large or small. From small agricultural shows to large sporting events, we supply to any size of event where safety of the public is an issue.

At JEF Group, we offer a total package which includes:

-    Advice on the amount, layout and type of security fencing panels required.
-    Delivery of the equipment anywhere in the UK.
-    Erect the equipment if required.
-    Dismantle, collect and load the security fencing panels after the event.
-    Steward the event if required.
-    Our very experienced staff always look smart and are easily identifiable in our company uniform.

At JEF Group we know how important the smooth running of your event is. JEF Group is a three generation family business with over 40 years experience. We are one of the largest providers of event equipment to events throughout the UK and Ireland.

Our all-inclusive prices are very competitive. If you would like to discuss your event, get more information about stages and rostrums or any of our other products or would like a free quotation, please telephone us on 01948 840192 or email John Foster (This email address is being protected from spambots. You need JavaScript enabled to view it.).

JEF Group can also supply many extras to make your event special.
Click here for more information about extras.

At JEF Group we take the Health and Safety very seriously.
Click here for more information about Health and Safety.

Related Events

  • Events supplied by JEF Group include:
  • The Open Golf Championship
  • The World Matchplay Championship
  • The Tour de France
  • The Potteries Marathon
  • The Wolverhampton Marathon
  • Newport Nocturne Britains only Floodlit cycle race

We have also supplied Royal visits - Game Shows, carnivals and processions.

Crowd Control Barriers

Crowd Control Barriers

Security Fencing

Security Fencing



Race Equipment

Race Equipment

Stages and Rostrums

Stages and Rostrums

Climbing and Abseil Towers

Climbing and Abseil Towers